Welcome to Ankush Softwares. These Terms & Conditions ("Terms") govern your access to and use of our website and the software development services we provide. By accessing this website or engaging our services, you agree to be bound by these Terms.
1. Use of Our Website
You may use this website for lawful purposes only. You agree not to misuse the site, attempt unauthorized access, or interfere with its normal operation. Content on this site is provided for general information about our services.
2. Services
Ankush Softwares provides custom software development, enterprise software solutions, SaaS application development, business management software, HRMS & payroll systems, and school & college ERP solutions. The specific scope, deliverables, timelines, and pricing for any engagement are defined in a separate written agreement or proposal.
3. Quotations & Engagements
- Estimates provided before a signed agreement are indicative and subject to change after detailed requirement analysis.
- Project work begins only after mutual written confirmation of scope and commercial terms.
- Changes to agreed scope may affect timelines and costs and will be handled through a change-request process.
4. Intellectual Property
All trademarks, logos, designs, and website content are the property of Ankush Softwares unless otherwise stated. Ownership of project deliverables is governed by the applicable project agreement and typically transfers upon full payment.
5. Client Responsibilities
Clients agree to provide accurate information, timely feedback, and any access or materials reasonably required to deliver the engaged services. Delays caused by pending client inputs may affect agreed timelines.
6. Payments
Payment terms, milestones, and schedules are defined in the relevant agreement. Late payments may result in suspension of work until outstanding amounts are settled.
7. Limitation of Liability
To the maximum extent permitted by law, Ankush Softwares shall not be liable for any indirect, incidental, or consequential damages arising from the use of this website or our services. Our total liability under any engagement is limited to the amounts paid for that specific engagement.
8. Third-Party Services
Our solutions may integrate with third-party platforms and cloud providers. We are not responsible for the availability, performance, or policies of such third parties.
9. Changes to These Terms
We may update these Terms from time to time. Continued use of the website after changes are posted constitutes acceptance of the revised Terms.
10. Governing Law
These Terms are governed by the laws of India, and any disputes shall be subject to the jurisdiction of the courts of Ghaziabad, Uttar Pradesh.
11. Contact
For any questions about these Terms, contact us at ankushsoftwares@gmail.com or call +91-9971516269.